SUTLEJ CONSTRUCTIONversusUNION TERRITORY OF CHANDIGARH

                          [2017] 12 S.C.R. 134


A                        SUTLEJ CONSTRUCTION
                                     v.
                UNION TERRITORY OF CHANDIGARH
                    (Civil Appeal No. 20885 of 2017)
B                          DECEMBER 05, 2017
      [J. CHELAMESWAR AND SANJAY KISHAN KAUL, JJ.]
          Arbitration:
           Award of contract - By respondent to appellant -
c   Termination of contract by respondent - Arbitration clause invoked
    - Award partly allowing claim of appellant and rejecting counter-
    claims of respondent - Objections against the award u/s. 34 of
    Arbitration and Conciliation Act, 1996, rejected by Addi. District
    Judge - High Court set aside the award - On appeal, held: When it
    comes to setting aside of an award under the public policy ground,
D
    the award should shock the conscience of the court and the court
    should not substitute its view for that of the arbitrator - An
    arbitrator is a chosen judge by the parties and it is on limited
    parameters that an award be inteifered with - High Court acted as
    if it was the first appellate court against a decree - The dispute had
E   resulted in a reasoned award after proper appreciation of evidence
    -Enforcement of award in toto is upheld.
          Allowing the appeal, the Court
          HELD: 1. The dispute in question had resulted in a
    reasoned award. It is not as if the arbitrator has not appreciated
F   the evidence. The arbitrator has taken a plausible view and the
    correct view. The ability of the appellant to comply with its
    obligations were inter dependent on the respondent meeting its
    obligations in time, to facilitate appropriate areas for· unloading
    of the earth and for its compacting. At least it is certainly a
G   plausible view. [Para 11] [140-B, D]
          2. When it comes to setting aside of an award under the
    public policy ground, it would mean that the award should shock
    the conscience of the court and would not include what the court
    thinks is unjust on the facts of the case seeking to substitute its
H
                                . 134
     SUTLEJ CONSTRUCTION v. UNION TERRITORY OF                           135
                   CHANDIGARH

view for that of the arbitrator to do what it considers to be            A
"justice." [Para 12] [140-E]
      Associate Builders v. Delhi Development Authority
      (2015) 3 sec 49 - relied on.
      3. The approach adopted by the Additional District Judge
was, thus, correct in not getting into the act of re-appreciating        B
the evidence as the first appellate court from a trial court
decree. An arbitrator is a chosen Judge by the parties and it is
on limited parameters can the award be interfered with. [Para
13] [140-F-G]
      Sudarsan Trading Co. v. The Government of Kerala                   c
      [1989] 1 SCR 665 ; Harish Chander & Co. v. State of
      U.P AIR 2016 SC 4257 : [2016] 8 SCR 773 ; Swan
      Gold Mining v. Hindustan Copper Limited 2014 (4)
      ArbLR 1 (SC) - relied on.
       4. The High Court ought to have restrained itself from            D
getting into the meanderings of evidence appreciation and
acting like a second appellate court. In fact, even in second
appeals, only questions of law are to be determined while the
first appellate court is the final court on facts. In the present case
the High Court has, thus, acted in the first appeal against              E
objections dismissed as if it was the first appellate court against
a decree passed by the trial court. The impugned order cannot
be sustained and is accordingly set aside and the enforcement of
the award in toto is upheld. [Paras 15-16] [141-A-B]
                       Case Law Reference
                                                                         F
        (2015) 3 sec 49                 relied on          Para 11
        [1989] 1 SCR 665                relied on         Para 12
        [2016] 8 SCR 773                relied on         Para 12
        2014 (4) ArbLR 1 (SC)           relied on         Par.a 12       G


     CIVIL APPELLATE JURISDICTION: Civil Appeal No. 20885
of2017.

                                                                         H
136             SUPREME COURT REPORTS                           [2017] 12 S.C.R.



A          From the Judgment and Order dated 01.04.2015 of the High Court
      of Punjab and Haryana at Chandigarh in F.A.O. No. 1621 of 2014
      (O&M).
             Nidhesh Gupta, Sr. Adv., Tarun Gupta, Puneet Varshney, Advs
      for the Appellant.
B           Rimali Batra, Ravi Prakash, Ms. Nikita Choukse, Chandra Prakash,
      U.T. Chandra Prakash, Advs for the Respondents ..
             The Judgment of the Court w~s delivered by
             SANJAY KISHAN KAUL, J. I. Leave granted.
C             2. The appellant was awarded a contract by the respondent of
      earth excavation work and loading into trucks and unloading for purposes
      of widening of the approach road Sukhna Choe on Chandigarh Kalka
      Road, Chandigarh vide memo No.201 dated 5.1.1996. The earth was
      required to be lifted from the first source near the regulator and carried
D     through trucks from Golf side initially. There was a second source of
      lifting the earth as per permission of the Superintendent Engineer but it
      is not necessary to go into the details of the contract for the present
      purposes. Suffice to say that the respondent alleges that the appellant
      did not fulfil its obligations while the appellant, on the other hand, alleges
      that what was required to be done by the respondent to facilitate execution
E     of the contract was not so done. This resulted in the respondent
      terminating the contract on 12.11.1996.
            3. The conditions of the contract provided for arbitration and despite
      the appellant invoking the arbitration clause, the Superintendent
      Engineer failed to nominate an Arbitrator resulting in the appellant
F     approaching the Court. In the course of the said proceedings Mr. R.N.
      Singal, retired District & Sessions Judge was appointed as an arbitrator
      in terms of order dated 31.7.2002 of the learned Civil Judge (Senior
      Division), Chandigarh.
             4. The parties put forth their respective claims before the arbitrator.
G     The appellant laid the claims while the respondent filed the counterclaims.
      The arbitrator made and published an Award dated 18.12.2013, partly
      allowing the claim of the appellant while rejecting the counterclaims of
      the respondent. The claims laid and the extent awarded as well as the
      counterclaims laid are as under:

H
     SUTLEJ CONSTRUCTION v. UNION TERRITORY OF                                      137
        CHANDIGARH [SANJAY KISHAN KAUL, J.]

                                                                                    A
Claims made b~· the Appellant                 Amounts awarded by the Arbitrator
S.Xo.       Particulars          Amount          Particulars       Amount(in
                                 (in J:\"R)                           L"'l,"R.)

I.      Balance pajment           2,00,014 Claim No.I and               1,20,299
        accruing from the last             amount deposited by            32,000    B
        running bill                       way of earnest

1.      Payment due on            1,11,231 Claim No.3                      65,076
        account of
        transportation oreanh
        not measured by                                                             c
        deparnnent
3.      Pa \ment due on             95,400 Claim No. 4                  7,74,375
        account ofless lead
        paid
4.      Idle hour charges of     31,22,280 Claim No.6                      45,435
        hea\'y earthmoving                                                          D
        machinery and labour
        deployed on the
        machillery

5.      Paymell! due on           1,69,206            --                 --
        account of earth                                                            E
        eroded by heavy rains
        due to non-
        compactiOll of earth
        and leaking water
        pipelines
6.      Payment on account          90,835            --                 --         F
        ofloss of profit on
        balance work

7.      Loss due to              12,80,000            -                  --
        prolongation ofwork
                                                                                    G
8.      Litigation expenses         25,000            -                  -

                Total            50,93,966          Total             10,37,185


                                                                                    H
138             SUPREME COURT REPORTS                         [2017] 12 S.C.R.


A           Interest@ 12% per annum was also allowed by the arbitrator in
      favour of the appellant.
        Counterclaims made by the Respondent
                Liquidated damages and the expe11ses [              8,01,808
B               incurred by it for completion of work I
                Loss due to delay in completion of work            20,00,000


                                   Tuia I                          28,01808
C            5. The respondent aggrieved by the Award filed objections under ·
      Section 34 of the Arbitration & Conciliatio:i Act, 1996 (hereinafter
      referred to as the 'said Act'), which were, however, rejected by the
      learned Additional District Judge, Chandigarh vide order dated 23.7.2013.
      The respondent thereafter preferred an appeal before the Punjab &
D     Haryana High Court and the said appeal succeeded whereby the Award
      was set aside opining that the contract was rightly terminated and the
      Department rightly imposed the penalty.
             6. ·We have heard learned counsel for the parties and have
      perused the record. The Award is a reasoned one. The arbitrator has
      taken note of the peculiar features of the contract inter se the parties
 E    that while the work of excavation of the earth, its loading into the trucks,
      unloading and transportation to site of the work was awarded to the
      appellant .as contractor, the spreading of the earth brought to the site of
      the work by the contractor and its compaction was to be done by the
      respondent Department itself. It is, thus, that the appellant claimed that
 F    even though they had taken up the work with right earnest to complete
      it within the scheduled period, the bi·eaches of the respondent has caused
      the delay. Such breaches enumerated are:
          a.     Obstruction in the disposal area due to overhead lines and
                 poles;
 G        b.     Delay in makirig available approached to the disposal site, wan
                  of lighting arrangement at the excavation as well as disposal
                  sites by the respondent;
           c.    Inadequate compaction plant and machinery. and other
                  auxiliary equipment
 H
     SUTLEJ CONSTRUCTION v. UNION TERRITORY OF                               139
        CHANDIGARH [SANJAY KISHAN KAUL, J.]

      It is in order to cover up their own lapses it is alleged that the     A
respondent chose to terminate the contract.
        7. The respondent, of course, denies the aforesaid allegations but
on the other hand contended that the work was carried on by the
appellant at slow pace leaving the respondent-Department with no
alternative but to levy penalty and to finally terminate the contract vide   B
letter dated 12.11.1996.
      8. In the opinion of the arbitrator the performance of the
contractual obligations by the appellant were dependent on reciprocal
performances by the respondent. On appreciation of evidence on record
it was concluded that the respondent had failed to comply with its           c
obligations and, thus, held the contract to be illegally terminated.
Thereafter the arbitrator, once again, on appreciation of evidence
decided to award the amounts as specified aforesaid.
       9. The learned Additional District Judge, Chandigarh while
dismissing the application of the respondent under Section 34 of the said D
Act came to the conclusion that the findings of the arbitrator were based
on appraisal of evidence and it was certainly not the function of the
Court to re-appreciate the evidence so long as it is not a case of
completely devoid of evidence. Since the spreading of the earth and its
compaction was required to be done by the respondent, the
non-carrying out of that activity would naturally impede the performance E
of the obligations by the appellant. Accessibility to the site was
obviously an important part of the execution of the contractual
obligations. In fact, the contract was carried over a period of four and a
half years against the original time period of 45 days, which would show
the unpreparedness of the respondent.                                      F
       10. The learned single Judge of the High Court, however, appears
to have made an endeavour to re-appreciate the evidence and sought to
come to a different conclusion than what was arrived at by the
arbitrator, the objections to which were dismissed by the learned
Additional District Judge, Chandigarh. The reasoning of the learned          G
single Judge is predicated on the absence of any contractual obligation
that the spreading of the earth brought to site was to be done by the
Department nor was there a stipulation that the overhead lines and poles
had to be removed by the respondent to make the area accessible. The

                                                                             H
140             SUPREME COURT REPORTS                           [2017) 12 S.C.R.



A     respondent-Department had not specified any space for unloading of
      the earth but only charges up to 5 kilometres were to be paid. Thus, the
      finding is that the arbitrator mis-conducted himself by acting contrary to
      the terms of the contract.
             11. We are not in agreement with the approach adopted by the
B     learned single Judge. The dispute in question had resulted in a reasoned
      award. It is not as if the arbitrator has not appreciated the evidence.
      The arbitrator has taken a plausible view and, an in our view, as per us
      the correct view, that the very nature of job to be performed would
      imply that there has to be an area for unloading and that too in the
      vicinity of 5 kilometres as that is all that the appellant was to be paid for.
C     The route was also determined. In such a situation to say that
      the respondent owed no obligation to make available the site cannot be
      accepted by any stretch of imagination. The unpreparedness of the
      respondent is also apparent from the fact that even post termination it
      took couple of years for the work to be carried out, which was meant to
D     be completed within 45 days. The ability of the appellant to comply with
      its obligations were inter dependent on the respondent meeting its
      obligations in time to facilitate appropriate areas for unloading of the
      earth and for its compacting. At least it is certainly a plausible view.
             12. It has been opined by this Court that when it comes to setting
 E    aside of ae it ward under the public policy ground, it would mean that the
      award should shock the conscience of the court and would not include
      what the court thinks is unjust on the facts of the case seeking to substitute
      its view for that of the arbitrator to do what it considers to be "justice."
      (Associate Builders v. Delhi Development Authority')
 F            13. The approach adopted by the learned Additional District Judge,
      Chandigarh was, thus, correct in not getting into the act of
      re-appreciating the evidence as the first appellate court from a trial court
      decree. An arbitrator is a chosen Judge by the parties and it is on limited
      parameters can the award be interfered with. (Sudarsan Trading Co.
      v. The Government of Kerala2; Barish Chander & Co. v. State of
 G    U.P. 3 and Swan Gold Mining v. Hindustan Copper Limited").

      • (2015) 3 sec 49
      2
        (1989) 1 SCR 665
      3
        AIR 2016 SC 4257
      4
        2014 (4) ArbLR I (SC)
 H
     SUTLEJ CONSTRUCTION v. UNION TERRITORY OF                                 141
        CHANDIGARH [SANJAY KISHAN KAUL, J.]

       15. The learned single Judge ought to have restrained himself           A
from getting into the meanderings of evidence appreciation and acting
like a second appellate court. In fact, even in second appeals, only
questions of law are to be determined while the first appellate court is
the final court on facts. In the present case the learned single Judge
has, thus, acted in the first appeal against objections dismissed as if it     B
was the first appellate court against a decree passed by the trial court.
      16. We have, thus, no hesitation in concluding that the impugned
order cannot be sustained and is accordingly set aside .and the
enforcement of the award in toto is upheld.
      17. The appeal is accordingly allowed but in the given facts of the      c
case we do not impose costs.


Kalpana K. Tripathy                                          Appeal allowed.